Terms & Conditions.

Welcome to Scorgie Interiors! These terms and conditions govern your use of our website and the services offered herein. By accessing or using our website, you agree to comply with and be bound by these terms.

Project Management a. Design Consultation: Our interior design services commence with an initial design consultation. During this consultation, we will discuss your requirements, preferences, and budget to formulate a design plan. b. Project Timeline: A project timeline will be established, outlining key milestones and deadlines. We will make reasonable efforts to adhere to this timeline, but unforeseen circumstances may cause adjustments. c. Client Cooperation: Timely client responses, approvals, and cooperation are crucial for project progression. Delays caused by the client may result in an extension of the project timeline.

Intellectual Property a. Ownership: All intellectual property rights, including but not limited to designs, plans, and specifications, created by Scorgie Interiors during the course of the project, remain the property of Scorgie Interiors unless otherwise agreed in writing. b. Client’s Use: Clients are granted a non-exclusive, non-transferable license to use the final design solely for the purpose of implementing the interior design project.

Limitation of Liability a. Indirect Damages: To the extent permitted by law, Scorgie Interiors shall not be liable for any indirect, consequential, incidental, or special damages arising out of or in connection with the services provided. b. Total Liability: In no event shall the total liability of Scorgie Interiors exceed the total fees paid by the client for the services rendered.

Governing Law These terms and conditions shall be governed by and construed in accordance with the laws of England and Wales. Any disputes arising out of or in connection with these terms shall be subject to the exclusive jurisdiction of the courts of England and Wales.

Third-Party Contractors Employed by the Client

a. Independent Contractors: Scorgie Interiors may collaborate with third-party tradespeople (contractors, suppliers, etc.) to execute certain aspects of the project. These parties operate as independent contractors.

b. Client-Engaged Contractors: If the client chooses to employ their contractors independently of Scorgie Interiors, it is expressly understood that those contractors are not under the control or responsibility of Scorgie Interiors.

c. Responsibility Disclaimer: Scorgie Interiors shall not be held responsible for the actions, performance, or conduct of contractors employed directly by the client. Any issues arising from their work or conduct must be addressed directly with the respective contractor.

d. Client Verification: Clients are solely responsible for verifying the qualifications, licenses, and insurance of any contractors they choose to engage independently. Scorgie Interiors is not liable for disputes, damages, or disagreements between the client and contractors engaged directly by the client.